1. Regulations
  2. title 48
  3. chapter 1
  4. part 42
  5. subpart 42.13
  6. § 42.1302

View all text of Subpart 42.13 [42.1301 - 42.1305]

42.1302 - 42.1302 Suspension of work.

A suspension of work under a construction or architect-engineer contract may be ordered by the contracting officer for a reasonable period of time. If the suspension is unreasonable, the contractor may submit a written claim for increases in the cost of performance, excluding profit.

AUTHORITY: 40 U.S.C. 121(c); 10 U.S.C. chapter 4 and 10 U.S.C. chapter 137 legacy provisions (see 10 U.S.C. 3016); and 51 U.S.C. 20113.

SOURCE: 48 FR 42370, Sept. 19, 1983, unless otherwise noted.

CITE AS: 48 CFR 42.1302